[1987]DLCA692 Login to Read Full Case <span style="font-size: 18px !important;"><span style="font-size: 18px !important;"><p class="MsoNormal" align="center" style="margin-bottom:5.0pt;text-align:center; mso-pagination:none;tab-stops:center 3.25in left 396.75pt"><b><span style="font-size:14.0pt;line-height:115%;font-family:"Book Antiqua","serif"; mso-bidi-font-family:Times;color:#548DD4;mso-themecolor:text2;mso-themetint: 153">AHEY LTD. <o:p></o:p></span></b></p><p class="MsoNormal" align="center" style="margin-bottom:5.0pt;text-align:center; mso-pagination:none;tab-stops:center 3.25in left 396.75pt"><b><span style="font-size:14.0pt;line-height:115%;font-family:"Book Antiqua","serif"; mso-bidi-font-family:Times;color:#548DD4;mso-themecolor:text2;mso-themetint: 153">vs. <o:p></o:p></span></b></p><p class="MsoNormal" align="center" style="margin-bottom:5.0pt;text-align:center; mso-pagination:none;tab-stops:center 3.25in left 396.75pt"><b><span style="font-size:14.0pt;line-height:115%;font-family:"Book Antiqua","serif"; mso-bidi-font-family:Times;color:#548DD4;mso-themecolor:text2;mso-themetint: 153">ARTHUR <o:p></o:p></span></b></p><p class="MsoNormal" align="center" style="margin-bottom:5.0pt;text-align:center; mso-pagination:none;tab-stops:center 3.25in left 396.75pt"><span style="font-size: 12pt; line-height: 115%; font-family: "Book Antiqua", serif;">[COURT OF APPEAL, ACCRA]<o:p></o:p></span></p><p class="MsoNormal" align="center" style="margin-bottom:5.0pt;text-align:center; mso-pagination:none"><b><span style="font-size: 12pt; line-height: 115%; font-family: "Book Antiqua", serif;">[1987-88] 1 GLR 19<o:p></o:p></span></b></p><div style="mso-element:para-border-div;border:none;border-bottom:solid windowtext 1.5pt; padding:0in 0in 1.0pt 0in"> <p class="MsoNoSpacing" align="right" style="text-align:right;line-height:115%; border:none;mso-border-bottom-alt:solid windowtext 1.5pt;padding:0in; mso-padding-alt:0in 0in 1.0pt 0in"><i><span style="font-size:12.0pt;line-height:115%;font-family:"Book Antiqua","serif"">DATE</span></i> <i><span style="font-size:12.0pt;line-height: 115%;font-family:"Book Antiqua","serif"">22 JANUARY 1987</span></i><span style="font-size:12.0pt;line-height:115%;font-family:"Book Antiqua","serif""><o:p></o:p></span></p> </div><p class="MsoNoSpacing" style="line-height:115%"><b><span style="font-size:12.0pt;line-height:115%;font-family:"Book Antiqua","serif"">COUNSEL: <o:p></o:p></span></b></p><div style="mso-element:para-border-div;border:none;border-bottom:solid windowtext 1.5pt; padding:0in 0in 0in 0in"> <p class="MsoNormal" style="text-align:justify;tab-stops:104.25pt;border:none; mso-border-bottom-alt:solid windowtext 1.5pt;padding:0in;mso-padding-alt:0in 0in 0in 0in"><span style="font-size:12.0pt;line-height:115%;font-family:"Book Antiqua","serif"; mso-bidi-font-family:Tahoma">KEDDEY FOR THE APPELLANT <o:p></o:p></span></p> <p class="MsoNormal" style="text-align:justify;tab-stops:104.25pt;border:none; mso-border-bottom-alt:solid windowtext 1.5pt;padding:0in;mso-padding-alt:0in 0in 0in 0in"><span style="font-size:12.0pt;line-height:115%;font-family:"Book Antiqua","serif"; mso-bidi-font-family:Tahoma">EBOW QUASHIE FOR THE RESPONDENT.<o:p></o:p></span></p> </div><p class="MsoNoSpacing" style="line-height:115%"><b><span style="font-size:12.0pt;line-height:115%;font-family:"Book Antiqua","serif"">CORAM: <o:p></o:p></span></b></p><div style="mso-element:para-border-div;border:none;border-bottom:solid windowtext 1.5pt; padding:0in 0in 0in 0in"> <p class="MsoNormal" style="margin-bottom:6.0pt;text-align:justify;border:none; mso-border-bottom-alt:solid windowtext 1.5pt;padding:0in;mso-padding-alt:0in 0in 0in 0in"><b><span style="font-size: 12pt; line-height: 115%; font-family: "Book Antiqua", serif;">OSEI-HWERE, WUAKU AND AMUA-SEKYI JJ.A<o:p></o:p></span></b></p> </div><p class="MsoNormal" style="margin-bottom:5.0pt;text-align:justify;mso-pagination: none;border:none;mso-padding-alt:31.0pt 31.0pt 31.0pt 31.0pt;mso-border-shadow: yes"><b><span style="font-size: 12pt; line-height: 115%; font-family: "Book Antiqua", serif;"><o:p> </o:p></span></b></p><p class="MsoNormal" style="margin-bottom:5.0pt;text-align:justify;mso-pagination: none;border:none;mso-padding-alt:31.0pt 31.0pt 31.0pt 31.0pt;mso-border-shadow: yes"><b><span style="font-size: 12pt; line-height: 115%; font-family: "Book Antiqua", serif;">JUDGMENT OF AMUA-SEKYI J.A.<o:p></o:p></span></b></p><p class="MsoNormal" style="margin-bottom:5.0pt;text-align:justify;mso-pagination: none;border:none;mso-padding-alt:31.0pt 31.0pt 31.0pt 31.0pt;mso-border-shadow: yes"><span style="font-size: 12pt; line-height: 115%; font-family: "Book Antiqua", serif;">Amua-Sekyi J.A. (delivering the first judgment at the invitation of Osei-Hwere J.A.). In April 1977 the plaintiff, Sarah Arthur, and the defendants entered into a building contract whereby the defendants agreed to construct for the plaintiff a two-storey block of three flats at Windy Ridge, Takoradi at a cost of ¢189,000. Construction was to be completed within ten months from the date of commencement of operations which was to be taken as the date on which the building permit was obtained. On the pleadings the parties are agreed that building operations were begun on 18 October 1977 and that the date for completion was 17 August 1978. By February 1980 the building had not been completed although the plaintiff had paid to the defendants the full value of the contract. On 6 February the parties met and agreed upon a variation of the contract by conversion of the roofing from aluminium to reinforced concrete. It was agreed that a further sum of ¢50,000 be paid by the plaintiff to the defendants to cover increased costs of labour and materials and that the completion date was now to be June 1980. The plaintiff paid ¢26,000 out of this sum. When, once again, the defendants defaulted on their obligations the plaintiff issued a writ in the High Court.<o:p></o:p></span></p><p class="MsoNormal" style="margin-bottom:5.0pt;text-align:justify;mso-pagination: none;border:none;mso-padding-alt:31.0pt 31.0pt 31.0pt 31.0pt;mso-border-shadow: yes"><span style="font-size: 12pt; line-height: 115%; font-family: "Book Antiqua", serif;"><o:p> </o:p></span></p><p class="MsoNormal" style="margin-bottom:5.0pt;text-align:justify;mso-pagination: none;border:none;mso-padding-alt:31.0pt 31.0pt 31.0pt 31.0pt;mso-border-shadow: yes"><span style="font-size: 12pt; line-height: 115%; font-family: "Book Antiqua", serif;">The defendants denied liability and blamed scarcity of building materials for their failure to complete the building. They referred to clause 10 (g) and (k) of the contract which provides:<o:p></o:p></span></p><p class="MsoNormal" style="margin-top:0in;margin-right:0in;margin-bottom:5.0pt; margin-left:.5in;text-align:justify;mso-pagination:none;border:none;mso-padding-alt: 31.0pt 31.0pt 31.0pt 31.0pt;mso-border-shadow:yes"><i><span style="font-size: 12pt; line-height: 115%; font-family: "Book Antiqua", serif;">“If ... the works are delayed by reason of . . . (g) delay in supplies of specified materials . . . (k) any other delay caused by circumstances beyond the control of the contractor, then the Employer shall grant a fair and reasonable extension of time for the completion of the works having regard to the amount of delay already so caused.”<o:p></o:p></span></i></p><p class="MsoNormal" style="margin-bottom:5.0pt;text-align:justify;mso-pagination: none;border:none;mso-padding-alt:31.0pt 31.0pt 31.0pt 31.0pt;mso-border-shadow: yes"><span style="font-size: 12pt; line-height: 115%; font-family: "Book Antiqua", serif;"><o:p> </o:p></span></p><p class="MsoNormal" style="margin-bottom:5.0pt;text-align:justify;mso-pagination: none;border:none;mso-padding-alt:31.0pt 31.0pt 31.0pt 31.0pt;mso-border-shadow: yes"><span style="font-size: 12pt; line-height: 115%; font-family: "Book Antiqua", serif;">They tendered in evidence two letters, one dated 23 June 1980 in which they complained of lack of iron rods, granite chippings and naco louvre frames and glasses and asked for a three-month extension of time, and the other dated 28 July 1980 in which they complained of lack of cement and paints and asked for a six-month extension. The plaintiff disputed the contention of the defendants that she agreed to either of these requests. It is however clear that even if she did, the date for completion had long expired when the matter came to trial. No further extension appears to have been sought or granted.<o:p></o:p></span></p><p class="MsoNormal" style="margin-bottom:5.0pt;text-align:justify;mso-pagination: none;border:none;mso-padding-alt:31.0pt 31.0pt 31.0pt 31.0pt;mso-border-shadow: yes"><span style="font-size: 12pt; line-height: 115%; font-family: "Book Antiqua", serif;"><o:p> </o:p></span></p><p class="MsoNormal" style="margin-bottom:5.0pt;text-align:justify;mso-pagination: none;border:none;mso-padding-alt:31.0pt 31.0pt 31.0pt 31.0pt;mso-border-shadow: yes"><span style="font-size: 12pt; line-height: 115%; font-family: "Book Antiqua", serif;">In the High Court the plaintiff was awarded damages under two heads, namely:<o:p></o:p></span></p><p class="MsoNormal" style="margin-bottom:5.0pt;text-align:justify;mso-pagination: none;border:none;mso-padding-alt:31.0pt 31.0pt 31.0pt 31.0pt;mso-border-shadow: yes"><span style="font-size: 12pt; line-height: 115%; font-family: "Book Antiqua", serif;">(a) ¢521,681 being the estimated cost of completing the building less the unpaid balance of ¢26,000;<o:p></o:p></span></p><p class="MsoNormal" style="margin-bottom:5.0pt;text-align:justify;mso-pagination: none;border:none;mso-padding-alt:31.0pt 31.0pt 31.0pt 31.0pt;mso-border-shadow: yes"><span style="font-size: 12pt; line-height: 115%; font-family: "Book Antiqua", serif;">(b) ¢50,400 being loss of rents at the rate of ¢1,200 per month from September 1978 to the date of judgment.<o:p></o:p></span></p><p class="MsoNormal" style="margin-bottom:5.0pt;text-align:justify;mso-pagination: none;border:none;mso-padding-alt:31.0pt 31.0pt 31.0pt 31.0pt;mso-border-shadow: yes"><span style="font-size: 12pt; line-height: 115%; font-family: "Book Antiqua", serif;"><o:p> </o:p></span></p><p class="MsoNormal" style="margin-bottom:5.0pt;text-align:justify;mso-pagination: none;border:none;mso-padding-alt:31.0pt 31.0pt 31.0pt 31.0pt;mso-border-shadow: yes"><span style="font-size: 12pt; line-height: 115%; font-family: "Book Antiqua", serif;">It is in respect of this judgment that the defendants have appealed to this court.<o:p></o:p></span></p><p class="MsoNormal" style="margin-bottom:5.0pt;text-align:justify;mso-pagination: none;border:none;mso-padding-alt:31.0pt 31.0pt 31.0pt 31.0pt;mso-border-shadow: yes"><span style="font-size: 12pt; line-height: 115%; font-family: "Book Antiqua", serif;">For the defendants, it has been urged that the proper thing for the plaintiff to have done on the determination of the contract was to complete the building and then sue for the actual cost of completion and, secondly, that the loss of rents, if any, ought to have been calculated from July 1980 and, in any case, that the plaintiff was not entitled to such rents up to the date of judgment. In this case, the plaintiff came to court without, it seems, making any attempt to complete the building herself. The record does not show that any questions were put to her in the court below to find out why, but in this court her counsel said she ha