[2016]DLCA8562 Login to Read Full Case <span style="font-size: 18px !important;"><p class="MsoNormal" align="center" style="margin-bottom:0cm;margin-bottom:.0001pt; text-align:center"><b><span lang="EN-US" style="font-size:12.0pt;line-height:115%;font-family:"Book Antiqua",serif; color:#00B0F0">JF-K COMPANY LTD</span></b><i><span lang="EN-US" style="font-size:12.0pt;line-height:115%;font-family:"Book Antiqua",serif"><o:p></o:p></span></i></p><p class="MsoNormal" align="center" style="margin-bottom:0cm;margin-bottom:.0001pt; text-align:center"><i><span lang="EN-US" style="font-size:10.0pt;line-height:115%;font-family:"Book Antiqua",serif">(PLAINTIFF/APPELLANT/RESPONDENT)</span></i><b><span lang="EN-US" style="font-size:10.0pt; line-height:115%;font-family:"Book Antiqua",serif;mso-fareast-font-family:"Times New Roman"; mso-bidi-font-family:"Times New Roman";color:#00B0F0"><o:p></o:p></span></b></p><p class="MsoNormal" align="center" style="margin-bottom:0cm;margin-bottom:.0001pt; text-align:center"><b><span lang="EN-GB" style="font-size:12.0pt;line-height:115%;font-family:"Book Antiqua",serif; mso-fareast-font-family:"Book Antiqua";mso-bidi-font-family:"Book Antiqua"; color:#00B0F0;mso-ansi-language:EN-GB">vs.<o:p></o:p></span></b></p><p class="MsoNormal" align="center" style="margin-bottom:0cm;margin-bottom:.0001pt; text-align:center"><b><span lang="EN-US" style="font-size:12.0pt;line-height:115%;font-family:"Book Antiqua",serif; color:#00B0F0">VOLVO TRUCK COMPANY<o:p></o:p></span></b></p><p class="MsoNoSpacing" align="center" style="text-align:center"><i><span lang="EN-US" style="font-size:10.0pt; font-family:"Book Antiqua",serif">(1<sup>ST</sup> DEFENDANT/RESPONDENT/CROSS APPELLANT)<o:p></o:p></span></i></p><p class="MsoNoSpacing" align="center" style="text-align:center"><b><span lang="EN-US" style="font-size:12.0pt; font-family:"Book Antiqua",serif;color:#00B0F0">MULTI-TECH (GH) LTD<o:p></o:p></span></b></p><p class="MsoNoSpacing" align="center" style="text-align:center"><i><span lang="EN-US" style="font-size:10.0pt; font-family:"Book Antiqua",serif">(2<sup>ND</sup> DEFENDANT/RESPONDENT)<o:p></o:p></span></i></p><p class="MsoNormal" align="center" style="margin-bottom:0cm;margin-bottom:.0001pt; text-align:center"><span lang="EN-GB" style="font-size:10.0pt;line-height:115%; font-family:"Book Antiqua",serif;mso-ansi-language:EN-GB">[COURT OF APPEAL, ACCRA]<o:p></o:p></span></p><div style="mso-element:para-border-div;border:none;border-bottom:solid windowtext 1.5pt; padding:0cm 0cm 1.0pt 0cm"> <p class="MsoNoSpacing" align="center" style="text-align:center;border:none; mso-border-bottom-alt:solid windowtext 1.5pt;padding:0cm;mso-padding-alt:0cm 0cm 1.0pt 0cm"><b><span lang="EN-US" style="font-size:10.0pt; font-family:"Book Antiqua",serif">CIVIL APPEAL NO. H1/13/2016 </span></b><span lang="EN-GB" style="font-size:12.0pt;font-family:"Book Antiqua",serif; mso-fareast-font-family:"Times New Roman";mso-ansi-language:EN-GB"> </span><span lang="EN-GB" style="font-size:10.0pt;font-family:"Book Antiqua",serif;mso-fareast-font-family: "Times New Roman";mso-ansi-language:EN-GB">DATE: </span><span lang="EN-GB" style="font-size:10.0pt;font-family:"Book Antiqua",serif;mso-ansi-language: EN-GB">17<sup>TH</sup> </span><span lang="EN-GB" style="font-size:10.0pt; font-family:"Book Antiqua",serif;mso-fareast-font-family:"Times New Roman"; mso-ansi-language:EN-GB">NOV, 2016</span><b><span lang="EN-US" style="font-size:10.0pt;font-family:"Book Antiqua",serif"><o:p></o:p></span></b></p> </div><p class="MsoNormal" style="margin-bottom:0cm;margin-bottom:.0001pt"><b><span lang="EN-GB" style="font-size:12.0pt; line-height:115%;font-family:"Book Antiqua",serif;mso-ansi-language:EN-GB">COUNSEL:<o:p></o:p></span></b></p><p class="MsoNoSpacing"><span lang="EN-US" style="font-size:12.0pt;font-family: "Book Antiqua",serif">FOSU GYEABOUR FOR THE PLAINTIFF/APPELLANT <o:p></o:p></span></p><div style="mso-element:para-border-div;border:none;border-bottom:solid windowtext 1.5pt; padding:0cm 0cm 1.0pt 0cm"> <p class="MsoNoSpacing" style="border:none;mso-border-bottom-alt:solid windowtext 1.5pt; padding:0cm;mso-padding-alt:0cm 0cm 1.0pt 0cm"><span lang="EN-US" style="font-size:12.0pt;font-family:"Book Antiqua",serif">IRIS A. ORLEANS FOR THE RESPONDENT <o:p></o:p></span></p> </div><p class="MsoNoSpacing"><b><span lang="EN-GB" style="font-size:12.0pt;font-family:"Book Antiqua",serif;mso-fareast-font-family: "Book Antiqua";mso-bidi-font-family:"Book Antiqua";mso-ansi-language:EN-GB">CORAM:</span></b><span lang="EN-US" style="font-size:12.0pt;font-family:"Book Antiqua",serif"><o:p></o:p></span></p><div style="mso-element:para-border-div;border:none;border-bottom:solid windowtext 1.5pt; padding:0cm 0cm 1.0pt 0cm"> <p class="MsoNoSpacing" style="border:none;mso-border-bottom-alt:solid windowtext 1.5pt; padding:0cm;mso-padding-alt:0cm 0cm 1.0pt 0cm"><span lang="EN-US" style="font-size:12.0pt;font-family:"Book Antiqua",serif">P. K. GYAESAYOR J.A. (PRESIDING), F.G. KORBIEH J.A, S. DZAMEFE J.A.<o:p></o:p></span></p> </div><p class="MsoNormal" style="margin-bottom:0cm;margin-bottom:.0001pt"><span lang="EN-GB" style="font-size:12.0pt;line-height:115%;font-family:"Book Antiqua",serif; mso-ansi-language:EN-GB"> <b><o:p></o:p></b></span></p><div style="mso-element:para-border-div;border:none;border-bottom:solid windowtext 1.5pt; padding:0cm 0cm 1.0pt 0cm"> <p class="MsoNormal" align="center" style="margin-bottom:0cm;margin-bottom:.0001pt; text-align:center;border:none;mso-border-bottom-alt:solid windowtext 1.5pt; padding:0cm;mso-padding-alt:0cm 0cm 1.0pt 0cm"><b><span lang="EN-GB" style="font-size:12.0pt;line-height:115%;font-family: "Book Antiqua",serif;mso-ansi-language:EN-GB">JUDGMENT<o:p></o:p></span></b></p> </div><p class="MsoNormal" style="text-align:justify;line-height:150%"><b><u><span lang="EN-US" style="font-size:12.0pt; line-height:150%;font-family:"Book Antiqua",serif;mso-bidi-font-family:Arial">F.G. KORBIEH, J.A.<o:p></o:p></span></u></b></p><p class="MsoNormal" style="text-align:justify;line-height:150%"><span lang="EN-US" style="font-size:12.0pt;line-height:150%;font-family:"Book Antiqua",serif; mso-bidi-font-family:Arial">Let me state right from the beginning that there are two appeals in this case both of which were filed under Order 8 of the Court of Appeal Rules, 1997 (C.I. 19). I will explain in more detail in due course. The genesis of the case leading up to the two appeals we are dealing with comprise of the following summary of facts. The plaintiff was at all material times a company incorporated under laws of Ghana. By its amended writ of summons filed on the 14<sup>th</sup> July, 2014, the plaintiff claimed against the two defendants jointly and severally special damages of (i) US$1,675,156.03 or its cedi equivalent and (ii) “GH¢5,000,000.00 plus 32% interest from March, 2013 till final date of payment being judgment debt from the reduction and cessation of operation of the tracks (sic) and trailers at the instance of the defendants” and general damages of ten million US dollars or its cedi equivalent. The plaintiff’s case was that it ordered 15 Volvo brand tipper trucks from the 1<sup>st</sup> defendant through the 2<sup>nd</sup> defendant to enable it “haul manganese and limestone”; but that when the trucks were put to use they were found to be defective hence the plaintiff was ordered by the defendants to cease operations in order for the defects to be rectified. In the meantime the parties (and the builder of the trailer parts of the trucks, Katmerciler from Turkey) had met and drawn up an action plan to enable the defendants rectify the defects on the vehicles so that the plaintiff could re-commence operations. Due to the delay in the implementation of the action plan by the defendants the plaintiff had “incurred huge losses and other (sic) and suffered other hardship and injuries such as operations, loss of contracts etc.” The plaintiff had therefore engaged the services of a valuer who had assessed the actual loss of income incurred by the plaintiff as a result of the defects on the trucks leading to the cessation of operations. The 1<sup>st</sup> defendant denied that it was liable to the plaintiff for its losses. It however admitted that it sold fifteen Volvo trucks to the plaintiff but stated that the trucks were covered by its International Warranty Terms and Conditions which “are applied for the 1<sup>st</sup> defendant’s sale of trucks globally.” The 1<sup>st</sup> defendant pleaded further that the International Warranty Terms and Conditions did not cover equipment/parts, superstructure or other installation work not assembled/installed by it and that this was expressly noted in the pro forma invoice evidencing the deal between the plaintiff and the 1<sup>st</sup> defendant. The 1<sup>st</sup> defendant had also conceded that there had been a meeting in Accra during which an action plan had been drawn up but averred that it had no contractual obligation to attend that meeting and that it attended the meeting only because it wanted to assist. It had also averred that the cause of the delay in implementing the action plan was beyond the control of the 1<sup>st</sup> defendant itself and its sub-supplier, the body-builder, Katmerciler. The 2<sup>nd</sup> defendant also denied that it was liable to the plaintiff for the claim. It denied that the fifteen trucks were imported from the 1<sup>st</sup> defendant through it and denied further that it was the 1<sup>st</sup> defendant’s agent for purposes of the importation of the trucks into Ghana. It denied that it ever ordered the plaintiff to cease operating the vehicles, alleging that it only acted as the mouthpiece of the 1<sup>st</sup> defendant in sending messages across to the plaintiff. The 2<sup>nd</sup> defendant also averred that it had attended the meeting in Accra at which the action plan was drawn up but averred that it had done so only as an after sales service provider of the 1<sup>st</sup> defendant’s brand of vehicles. <o:p></o:p></span></p><p class="MsoNormal" style="text-align:justify;line-height:150%"><span lang="EN-US" style="font-size:12.0pt;line-height:150%;font-family:"Book Antiqua",serif; mso-bidi-font-family:Arial">At the close of pleadings five substantive issues were set down for trial. At the trial, the plaintiff testified through its Chief Executive Officer, Jeffrey Koranteng and one other witness. The witnesses for the defendants were simply listed as DW1 and DW2. It is therefore not clear whether they represented the two defendants respectively or were merely witnesses for the defence. Be that as it may. I shall proceed on the assumption that they represented the two defendants respectively since a party must be given a hearing before judgment is pro